STATEMENT OF WORK
SOW Number: [________________________________]
Effective Date: [__/__/____]
Master Agreement Reference: [________________________________] (if applicable)
PARTIES
CLIENT:
Name: [________________________________]
Address: [________________________________]
City, State, ZIP: [________________________________], Wyoming [____]
County: [________________________________]
Contact Person: [________________________________]
Title: [________________________________]
Email: [________________________________]
Phone: [________________________________]
PROVIDER:
Name: [________________________________]
Address: [________________________________]
City, State, ZIP: [________________________________]
Contact Person: [________________________________]
Title: [________________________________]
Email: [________________________________]
Phone: [________________________________]
RECITALS
WHEREAS, Client desires to engage Provider to perform certain professional services as described herein; and
WHEREAS, Provider represents that it possesses the necessary qualifications, experience, and expertise to perform such services in accordance with applicable Wyoming professional standards; and
WHEREAS, the Parties wish to set forth the terms and conditions under which Provider shall perform the work described herein, in compliance with the laws of the State of Wyoming;
NOW, THEREFORE, in consideration of the mutual covenants and agreements set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties agree as follows:
1. PROJECT DESCRIPTION
1.1 Project Title
[________________________________]
1.2 Project Overview
[________________________________]
[________________________________]
[________________________________]
1.3 Business Objectives
The objectives of this engagement include:
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
1.4 Background and Context
[________________________________]
[________________________________]
[________________________________]
2. SCOPE OF WORK
2.1 Services to Be Performed
Provider shall perform the following services (collectively, the "Services"):
Phase 1: [________________________________]
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
Phase 2: [________________________________]
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
Phase 3: [________________________________]
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
2.2 Specific Tasks and Activities
| Task ID | Task Description | Responsible Party | Estimated Hours |
|---|---|---|---|
| [____] | [________________________________] | ☐ Provider ☐ Client | [____] |
| [____] | [________________________________] | ☐ Provider ☐ Client | [____] |
| [____] | [________________________________] | ☐ Provider ☐ Client | [____] |
| [____] | [________________________________] | ☐ Provider ☐ Client | [____] |
| [____] | [________________________________] | ☐ Provider ☐ Client | [____] |
| [____] | [________________________________] | ☐ Provider ☐ Client | [____] |
| [____] | [________________________________] | ☐ Provider ☐ Client | [____] |
| [____] | [________________________________] | ☐ Provider ☐ Client | [____] |
2.3 Exclusions from Scope
The following items are expressly excluded from this Statement of Work:
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
2.4 Out-of-Scope Work Procedures
Any work not specifically described in Section 2.1 or Section 2.2 shall be considered out-of-scope and shall require a written Change Order executed by both Parties prior to commencement.
3. DELIVERABLES
3.1 Deliverables Table
| Deliverable ID | Deliverable Description | Format/Medium | Due Date | Acceptance Criteria Reference |
|---|---|---|---|---|
| D-[____] | [________________________________] | [________________________________] | [__/__/____] | Section 5.[____] |
| D-[____] | [________________________________] | [________________________________] | [__/__/____] | Section 5.[____] |
| D-[____] | [________________________________] | [________________________________] | [__/__/____] | Section 5.[____] |
| D-[____] | [________________________________] | [________________________________] | [__/__/____] | Section 5.[____] |
| D-[____] | [________________________________] | [________________________________] | [__/__/____] | Section 5.[____] |
| D-[____] | [________________________________] | [________________________________] | [__/__/____] | Section 5.[____] |
3.2 Deliverable Specifications
Deliverable D-[____]: [________________________________]
Description: [________________________________]
Format Requirements: [________________________________]
Technical Specifications: [________________________________]
Quality Standards: [________________________________]
Deliverable D-[____]: [________________________________]
Description: [________________________________]
Format Requirements: [________________________________]
Technical Specifications: [________________________________]
Quality Standards: [________________________________]
Deliverable D-[____]: [________________________________]
Description: [________________________________]
Format Requirements: [________________________________]
Technical Specifications: [________________________________]
Quality Standards: [________________________________]
3.3 Delivery Method
Deliverables shall be provided to Client via:
☐ Email to: [________________________________]
☐ Secure file transfer to: [________________________________]
☐ Physical delivery to: [________________________________]
☐ Cloud storage platform: [________________________________]
☐ Other: [________________________________]
4. MILESTONES AND TIMELINE
4.1 Project Schedule
| Milestone ID | Milestone Description | Start Date | End Date | Dependencies |
|---|---|---|---|---|
| M-[____] | Project Kickoff | [__/__/____] | [__/__/____] | None |
| M-[____] | [________________________________] | [__/__/____] | [__/__/____] | [____] |
| M-[____] | [________________________________] | [__/__/____] | [__/__/____] | [____] |
| M-[____] | [________________________________] | [__/__/____] | [__/__/____] | [____] |
| M-[____] | [________________________________] | [__/__/____] | [__/__/____] | [____] |
| M-[____] | [________________________________] | [__/__/____] | [__/__/____] | [____] |
| M-[____] | Final Delivery and Acceptance | [__/__/____] | [__/__/____] | [____] |
4.2 Key Dates
Project Commencement Date: [__/__/____]
Estimated Completion Date: [__/__/____]
Contract Expiration Date: [__/__/____]
4.3 Schedule Assumptions
The project schedule is based on the following assumptions:
☐ Client will provide all required information and approvals within [____] business days of request
☐ Client resources will be available as specified in Section 8
☐ No material changes to scope will occur during the project
☐ [________________________________]
☐ [________________________________]
4.4 Schedule Contingencies
In the event of delays caused by Client, the project timeline shall be extended by a period equal to the delay, and any resulting additional costs shall be borne by Client. Provider shall notify Client in writing within [____] business days of becoming aware of any delay or potential delay.
5. ACCEPTANCE CRITERIA
5.1 General Acceptance Standards
All Deliverables shall:
☐ Conform to the specifications set forth in this SOW
☐ Be free from material defects
☐ Meet industry standards for quality and workmanship
☐ Comply with all applicable Wyoming and federal laws and regulations
☐ [________________________________]
5.2 Specific Acceptance Criteria by Deliverable
Deliverable D-[____]:
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
Deliverable D-[____]:
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
Deliverable D-[____]:
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
5.3 Acceptance Process
5.3.1 Upon delivery of each Deliverable, Client shall have [____] business days (the "Review Period") to review and either accept or reject the Deliverable.
5.3.2 Acceptance or rejection shall be communicated in writing to Provider.
5.3.3 If Client rejects a Deliverable, Client shall provide written notice specifying in reasonable detail the deficiencies or non-conformities.
5.3.4 Provider shall have [____] business days to cure any identified deficiencies and resubmit the Deliverable.
5.3.5 If Client fails to respond within the Review Period, the Deliverable shall be deemed accepted.
5.4 Final Acceptance
Final acceptance of all Services and Deliverables shall be evidenced by Client's execution of a written acceptance certificate or by Client's payment of the final invoice, whichever occurs first.
6. FEES AND PAYMENT TERMS
6.1 Compensation Structure
☐ Fixed Price: Total contract value of $[________________________________]
☐ Time and Materials:
- Hourly rate: $[____]/hour
- Estimated hours: [____]
- Not-to-exceed amount: $[________________________________]
☐ Milestone-Based Payments: As set forth in Section 6.2
☐ Retainer: Monthly retainer of $[________________________________]
☐ Other: [________________________________]
6.2 Payment Schedule
| Payment | Description | Amount | Due Date/Trigger |
|---|---|---|---|
| 1 | [________________________________] | $[________________________________] | [________________________________] |
| 2 | [________________________________] | $[________________________________] | [________________________________] |
| 3 | [________________________________] | $[________________________________] | [________________________________] |
| 4 | [________________________________] | $[________________________________] | [________________________________] |
| 5 | Final Payment | $[________________________________] | Upon Final Acceptance |
TOTAL CONTRACT VALUE: $[________________________________]
6.3 Invoicing
6.3.1 Provider shall submit invoices to Client at the address/email specified in the Parties section or as otherwise directed by Client.
6.3.2 Invoices shall include: SOW number, invoice number, invoice date, description of services rendered, hours worked (if applicable), expenses incurred, and total amount due.
6.3.3 Payment shall be due within [____] days of Client's receipt of a proper invoice.
6.4 Expenses
☐ All expenses are included in the fees stated above
☐ Client shall reimburse Provider for pre-approved, reasonable out-of-pocket expenses, including:
☐ Travel expenses (at [________________________________] rates)
☐ Lodging (not to exceed $[____] per night)
☐ Meals (not to exceed $[____] per day)
☐ Materials and supplies
☐ Other: [________________________________]
Maximum reimbursable expenses: $[________________________________]
6.5 Late Payment — Wyoming Statutory Interest
Payments not received within [____] days of the due date shall accrue interest at the rate of [____]% per annum, or, if no rate is specified, at the statutory rate provided under WS § 40-14-106 (currently seven percent (7%) per annum when no rate is contractually agreed), calculated from the due date until payment is received. Provider shall also be entitled to recover reasonable costs of collection, including attorney's fees, as permitted under Wyoming law.
6.6 Taxes
Unless otherwise specified, all fees are exclusive of applicable taxes. Client shall be responsible for all sales and use taxes arising from the Services, except for taxes based on Provider's income. Wyoming imposes a state sales tax (WS § 39-15-101 et seq.) on certain goods and services at a rate of 4.0%, with optional county taxes up to an additional 2.0%. Wyoming does not impose a state income tax on individuals or corporations. Each Party is independently responsible for its own tax obligations arising from this SOW.
7. CHANGE ORDER PROCESS
7.1 Change Request Initiation
Either Party may request a change to this SOW by submitting a written Change Request to the other Party. The Change Request shall include:
☐ Description of the proposed change
☐ Reason for the change
☐ Impact on scope, timeline, and budget
☐ Any other relevant information
7.2 Change Request Evaluation
7.2.1 Upon receipt of a Change Request, Provider shall evaluate the request and provide Client with a written Change Order proposal within [____] business days.
7.2.2 The Change Order proposal shall specify:
(a) Detailed description of the change
(b) Impact on project schedule
(c) Impact on project costs
(d) Any modifications to Acceptance Criteria
(e) Any other material impacts
7.3 Change Order Approval
7.3.1 No change shall be implemented until a Change Order has been executed by authorized representatives of both Parties.
7.3.2 Changes agreed to verbally or via email shall not be binding unless subsequently documented in a written Change Order signed by both Parties, consistent with Wyoming's Statute of Frauds (WS § 1-23-105) for agreements not to be performed within one year.
7.4 Change Order Form
Each Change Order shall include:
- Change Order Number: CO-[____]
- SOW Reference: [________________________________]
- Date: [__/__/____]
- Description of Change: [________________________________]
- Schedule Impact: [________________________________]
- Cost Impact: $[________________________________]
- Revised Total Contract Value: $[________________________________]
- Authorized Signatures of both Parties
7.5 Emergency Changes
In the event of an emergency requiring immediate action to prevent harm or significant loss, Provider may proceed with reasonable changes without prior written approval, provided that:
(a) Provider notifies Client as soon as practicable
(b) A Change Order is executed within [____] business days following the emergency
(c) Additional compensation is limited to Provider's reasonable costs plus [____]%
8. ASSUMPTIONS AND DEPENDENCIES
8.1 Client Assumptions
This SOW is based on the following assumptions regarding Client:
☐ Client shall provide timely access to necessary personnel, information, systems, and facilities
☐ Client shall designate a primary point of contact with authority to make decisions
☐ Client shall review and approve deliverables within the timeframes specified
☐ Client shall provide complete and accurate information as reasonably requested
☐ Client's existing systems and infrastructure are compatible with the proposed solution
☐ [________________________________]
☐ [________________________________]
8.2 Provider Assumptions
This SOW is based on the following assumptions regarding Provider:
☐ Provider has the necessary skills, resources, and expertise to perform the Services
☐ Provider shall assign qualified personnel to the project
☐ Provider shall maintain appropriate insurance coverage throughout the engagement, including workers' compensation coverage through the Wyoming Workers' Compensation Division
☐ [________________________________]
☐ [________________________________]
8.3 Technical Assumptions
☐ [________________________________]
☐ [________________________________]
☐ [________________________________]
8.4 Dependencies
| Dependency ID | Description | Responsible Party | Required By Date |
|---|---|---|---|
| DEP-[____] | [________________________________] | ☐ Client ☐ Provider ☐ Third Party | [__/__/____] |
| DEP-[____] | [________________________________] | ☐ Client ☐ Provider ☐ Third Party | [__/__/____] |
| DEP-[____] | [________________________________] | ☐ Client ☐ Provider ☐ Third Party | [__/__/____] |
| DEP-[____] | [________________________________] | ☐ Client ☐ Provider ☐ Third Party | [__/__/____] |
8.5 Assumption Failure
If any assumption proves to be incorrect or any dependency is not met, Provider shall notify Client promptly, and the Parties shall negotiate in good faith to address any resulting impact on scope, schedule, or budget through the Change Order process.
9. RESOURCES AND PERSONNEL
9.1 Provider Resources
Provider shall assign the following personnel to this engagement:
| Role | Name | Responsibilities | Estimated Time Commitment |
|---|---|---|---|
| Project Manager | [________________________________] | [________________________________] | [____]% |
| [________________________________] | [________________________________] | [________________________________] | [____]% |
| [________________________________] | [________________________________] | [________________________________] | [____]% |
| [________________________________] | [________________________________] | [________________________________] | [____]% |
9.2 Key Personnel
The following individuals are designated as Key Personnel and may not be removed or replaced without Client's prior written consent, which shall not be unreasonably withheld:
☐ [________________________________], [Title]
☐ [________________________________], [Title]
☐ [________________________________], [Title]
9.3 Personnel Replacement
9.3.1 If any Key Personnel becomes unavailable due to resignation, illness, or other circumstances beyond Provider's control, Provider shall promptly notify Client and propose a replacement of comparable qualifications and experience.
9.3.2 Client shall have [____] business days to approve or reject the proposed replacement.
9.3.3 Provider shall ensure adequate knowledge transfer to any replacement personnel at no additional cost to Client.
9.4 Client Resources
Client shall provide the following resources and personnel:
| Role | Name | Responsibilities | Availability |
|---|---|---|---|
| Project Sponsor | [________________________________] | [________________________________] | [________________________________] |
| Client Project Manager | [________________________________] | [________________________________] | [________________________________] |
| Subject Matter Expert(s) | [________________________________] | [________________________________] | [________________________________] |
| [________________________________] | [________________________________] | [________________________________] | [________________________________] |
9.5 Work Location
Services shall be performed at:
☐ Provider's facilities
☐ Client's facilities located at: [________________________________]
☐ Remote/virtual
☐ Combination: [________________________________]
10. PROJECT GOVERNANCE
10.1 Project Management
10.1.1 Provider's Project Manager shall be responsible for day-to-day management of the Services and shall serve as the primary point of contact for Client.
10.1.2 Client's Project Manager shall be responsible for coordinating Client's activities and resources and shall serve as the primary point of contact for Provider.
10.2 Communication Protocols
Status Reports:
Provider shall provide written status reports to Client on a ☐ weekly ☐ bi-weekly ☐ monthly basis. Status reports shall include:
☐ Summary of work completed during the reporting period
☐ Work planned for the next reporting period
☐ Issues, risks, and concerns
☐ Budget and schedule status
☐ Change Order status
☐ Action items requiring Client attention
Status Meetings:
☐ Weekly status meetings on [________________________________] at [____] ☐ AM ☐ PM (Mountain Time)
☐ Monthly executive reviews on [________________________________]
☐ Ad hoc meetings as needed
10.3 Escalation Procedures
Level 1 — Project Manager Level:
Issues shall first be addressed by the Project Managers. Resolution expected within [____] business days.
Provider Contact: [________________________________]
Client Contact: [________________________________]
Level 2 — Director/Management Level:
If unresolved at Level 1, issues shall be escalated to management. Resolution expected within [____] business days.
Provider Contact: [________________________________]
Client Contact: [________________________________]
Level 3 — Executive Level:
If unresolved at Level 2, issues shall be escalated to executive leadership. Resolution expected within [____] business days.
Provider Contact: [________________________________]
Client Contact: [________________________________]
10.4 Decision Authority
| Decision Type | Client Authority | Provider Authority |
|---|---|---|
| Scope Changes | [________________________________] | [________________________________] |
| Budget Changes | [________________________________] | [________________________________] |
| Schedule Changes | [________________________________] | [________________________________] |
| Technical Decisions | [________________________________] | [________________________________] |
| Personnel Changes | [________________________________] | [________________________________] |
10.5 Documentation and Records
Provider shall maintain complete and accurate records of all Services performed, including time records, correspondence, meeting minutes, and technical documentation. Such records shall be maintained for a minimum of ten (10) years consistent with Wyoming's statute of limitations for written contracts under WS § 1-3-105 and shall be made available to Client upon reasonable request.
11. INTELLECTUAL PROPERTY AND WORK PRODUCT
11.1 Work Product Ownership
All work product, deliverables, inventions, discoveries, improvements, and materials created by Provider in the performance of this SOW (collectively, "Work Product") shall be the sole and exclusive property of Client.
11.2 Assignment of Rights
Provider hereby assigns and agrees to assign to Client all right, title, and interest in and to the Work Product, including all intellectual property rights therein (patents, copyrights, trade secrets, and trademarks).
11.3 Provider Pre-Existing Materials
Provider retains all rights in its pre-existing intellectual property, tools, methodologies, and know-how ("Provider Materials"). To the extent any Provider Materials are incorporated into the Work Product, Provider grants Client a perpetual, non-exclusive, royalty-free, worldwide license to use, modify, and sublicense such Provider Materials solely as part of the Work Product.
11.4 Third-Party Materials
Provider shall not incorporate any third-party materials into the Work Product without Client's prior written consent. If third-party materials are used with Client's approval, Provider shall secure all necessary licenses and rights for Client's intended use.
11.5 Work Made for Hire
To the extent permitted under applicable law, all Work Product that qualifies as a "work made for hire" under the U.S. Copyright Act (17 U.S.C. § 101) shall be deemed a work made for hire.
11.6 Cooperation
Provider shall execute all documents and take all actions reasonably requested by Client to perfect Client's rights in the Work Product.
12. CONFIDENTIALITY
12.1 Definition
"Confidential Information" means any non-public information disclosed by either Party to the other Party in connection with this SOW, whether oral, written, electronic, or visual, including business plans, financial data, technical information, customer lists, trade secrets, and proprietary methodologies.
12.2 Obligations
The receiving Party shall:
(a) Use Confidential Information solely for the purposes of this SOW
(b) Not disclose Confidential Information to any third party without the disclosing Party's prior written consent
(c) Protect Confidential Information with the same degree of care as it uses for its own confidential information, but no less than reasonable care
(d) Limit access to Confidential Information to those employees, agents, and subcontractors who have a need to know and who are bound by confidentiality obligations no less protective than those herein
12.3 Exceptions
Confidential Information does not include information that:
(a) Is or becomes publicly available through no fault of the receiving Party
(b) Was already in the receiving Party's possession without restriction prior to disclosure
(c) Is independently developed by the receiving Party without use of or reference to the disclosing Party's Confidential Information
(d) Is lawfully received from a third party without restriction on disclosure
(e) Is required to be disclosed by law, regulation, or court order, provided that the receiving Party gives the disclosing Party prompt written notice and cooperates in seeking a protective order
12.4 Wyoming Trade Secrets
The Parties acknowledge that certain Confidential Information may constitute "trade secrets" as defined under the Wyoming Uniform Trade Secrets Act (WS § 40-24-101 et seq.). Under WS § 40-24-101(a)(iv), a "trade secret" means information, including a formula, pattern, compilation, program, device, method, technique, or process that derives independent economic value, actual or potential, from not being generally known to, and not being readily ascertainable by proper means by, other persons who can obtain economic value from its disclosure or use, and is the subject of efforts that are reasonable under the circumstances to maintain its secrecy. Misappropriation of trade secrets may give rise to injunctive relief under WS § 40-24-102 and damages under WS § 40-24-103, including recovery of actual damages and unjust enrichment, and in cases of willful and malicious misappropriation, exemplary damages not exceeding twice the amount of actual damages. Under WS § 40-24-105, an action for misappropriation must be brought within three (3) years after the misappropriation is discovered or by the exercise of reasonable diligence should have been discovered.
12.5 Duration
Confidentiality obligations shall survive termination or expiration of this SOW for a period of [____] years, or, with respect to trade secrets, for so long as such information qualifies as a trade secret under Wyoming law.
13. WARRANTY
13.1 Services Warranty
Provider warrants that:
(a) All Services shall be performed in a professional and workmanlike manner consistent with industry standards
(b) All Services shall be performed by qualified personnel with the requisite skills, training, and experience
(c) All Services shall conform to the specifications and requirements set forth in this SOW
(d) All Services shall comply with applicable Wyoming and federal laws, regulations, and industry standards
13.2 Deliverables Warranty
Provider warrants that all Deliverables shall:
(a) Conform to the specifications and acceptance criteria set forth in this SOW
(b) Be free from material defects in design and workmanship
(c) Perform in accordance with any documentation or specifications provided
(d) Not infringe upon any third-party intellectual property rights
13.3 Warranty Period
The warranty period shall be [____] months from the date of Final Acceptance (the "Warranty Period").
13.4 Warranty Remedies
13.4.1 During the Warranty Period, if any Deliverable or Service fails to conform to the warranties set forth herein, Client shall notify Provider in writing of such non-conformance.
13.4.2 Upon receipt of such notice, Provider shall, at no additional cost to Client:
☐ Re-perform the non-conforming Services; and/or
☐ Repair or replace the non-conforming Deliverable
13.4.3 Such remedy shall be completed within [____] business days of Provider's receipt of notice, unless otherwise agreed by the Parties.
13.5 Warranty Exclusions
The warranties set forth herein shall not apply to defects or non-conformances caused by:
(a) Client's misuse, neglect, or improper operation
(b) Modifications made by Client or third parties without Provider's authorization
(c) Use in combination with materials or equipment not specified by Provider
(d) Client's failure to follow Provider's written instructions or recommendations
(e) Force majeure events
13.6 Disclaimer
EXCEPT AS EXPRESSLY SET FORTH IN THIS SOW, PROVIDER MAKES NO OTHER WARRANTIES, EXPRESS OR IMPLIED, INCLUDING WITHOUT LIMITATION ANY IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, OR NON-INFRINGEMENT. THIS DISCLAIMER SHALL NOT LIMIT OR AFFECT ANY WARRANTIES THAT CANNOT BE EXCLUDED UNDER APPLICABLE WYOMING LAW.
14. INDEMNIFICATION
14.1 Provider Indemnification
Provider shall indemnify, defend, and hold harmless Client and its officers, directors, employees, agents, and affiliates from and against any and all third-party claims, damages, losses, liabilities, costs, and expenses (including reasonable attorney's fees) arising out of or related to:
(a) Provider's breach of any representation, warranty, or obligation under this SOW
(b) Provider's gross negligence or willful misconduct in the performance of Services
(c) Any claim that the Work Product or Deliverables infringe upon any third-party intellectual property rights
(d) Provider's violation of any applicable Wyoming or federal law or regulation
(e) Any personal injury or property damage caused by Provider's personnel in the performance of Services
14.2 Client Indemnification
Client shall indemnify, defend, and hold harmless Provider and its officers, directors, employees, agents, and affiliates from and against any and all third-party claims, damages, losses, liabilities, costs, and expenses (including reasonable attorney's fees) arising out of or related to:
(a) Client's breach of any representation, warranty, or obligation under this SOW
(b) Client's gross negligence or willful misconduct
(c) Client's use of the Deliverables in a manner not contemplated by this SOW
(d) Any materials or information provided by Client that infringe upon third-party rights
14.3 Indemnification Procedures
14.3.1 The indemnified Party shall give prompt written notice to the indemnifying Party of any claim for which indemnification is sought.
14.3.2 The indemnifying Party shall have the right to control the defense and settlement of any such claim, provided that no settlement shall impose any obligation on the indemnified Party without its prior written consent.
14.3.3 The indemnified Party shall cooperate fully with the indemnifying Party in the defense of any claim.
14.4 Wyoming Workers' Compensation Limitation
The Parties acknowledge that under Wyoming's Workers' Compensation Act (WS § 27-14-101 et seq.), an employer's liability for workplace injuries is generally limited to workers' compensation benefits. The exclusive remedy provisions of WS § 27-14-104 apply, meaning workers' compensation is the exclusive remedy for a worker's injury or death against an employer. Nothing in this Section 14 is intended to create liability beyond what is permitted under Wyoming law.
15. LIMITATION OF LIABILITY
15.1 Cap on Liability
EXCEPT FOR OBLIGATIONS UNDER SECTION 12 (CONFIDENTIALITY), SECTION 14 (INDEMNIFICATION FOR IP INFRINGEMENT), AND PROVIDER'S GROSS NEGLIGENCE OR WILLFUL MISCONDUCT, EACH PARTY'S AGGREGATE LIABILITY UNDER THIS SOW SHALL NOT EXCEED THE TOTAL FEES PAID OR PAYABLE BY CLIENT TO PROVIDER UNDER THIS SOW DURING THE TWELVE (12) MONTH PERIOD PRECEDING THE CLAIM (OR $[________________________________], WHICHEVER IS GREATER).
15.2 Exclusion of Consequential Damages
IN NO EVENT SHALL EITHER PARTY BE LIABLE TO THE OTHER FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, OR PUNITIVE DAMAGES, INCLUDING LOST PROFITS, LOST REVENUE, LOSS OF DATA, OR BUSINESS INTERRUPTION, REGARDLESS OF THE THEORY OF LIABILITY, EVEN IF SUCH PARTY HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.
15.3 Wyoming Law Considerations
Nothing in this Section 15 shall be construed to limit any liability that cannot be limited under applicable Wyoming law, including liability for fraud or for damages arising from bodily injury or death caused by negligence. Wyoming applies a modified comparative fault system under WS § 1-1-109, where a claimant's recovery is reduced by the percentage of fault attributed to the claimant.
16. WYOMING-SPECIFIC PROVISIONS
16.1 Governing Law
This Statement of Work and all matters arising out of or relating to this SOW shall be governed by and construed in accordance with the laws of the State of Wyoming, without regard to its conflict of law provisions.
16.2 Venue and Jurisdiction
Any action or proceeding arising out of or relating to this SOW shall be brought exclusively in the state courts located in ☐ Laramie County ☐ Natrona County ☐ Teton County ☐ Albany County ☐ [________________________________] County, Wyoming, or in the United States District Court for the District of Wyoming (Cheyenne or Casper), and each Party irrevocably submits to the exclusive jurisdiction of such courts.
Common venue selections in Wyoming:
| County | City | Federal Court |
|---|---|---|
| Laramie County | Cheyenne | U.S. District Court for the District of Wyoming (Cheyenne) |
| Natrona County | Casper | U.S. District Court for the District of Wyoming (Casper) |
| Albany County | Laramie | U.S. District Court for the District of Wyoming (Cheyenne) |
| Teton County | Jackson | U.S. District Court for the District of Wyoming (Casper) |
| Fremont County | Lander / Riverton | U.S. District Court for the District of Wyoming (Casper) |
| Sweetwater County | Rock Springs / Green River | U.S. District Court for the District of Wyoming (Cheyenne) |
| Campbell County | Gillette | U.S. District Court for the District of Wyoming (Casper) |
Note: Wyoming has only one federal judicial district — the United States District Court for the District of Wyoming — with courthouses in Cheyenne and Casper.
16.3 Statute of Frauds Compliance
This SOW is intended to comply with Wyoming's Statute of Frauds (WS § 1-23-105) and shall be executed in writing and signed by the Parties. Pursuant to WS § 1-23-105(a)(v), every agreement that by its terms is not to be performed within one year from the making thereof shall be void unless such agreement, or some note or memorandum thereof, is in writing and subscribed by the party to be charged.
16.4 Statute of Limitations
The Parties acknowledge that under WS § 1-3-105(a)(i), any action upon a specialty or any contract, agreement, or promise in writing shall be brought within ten (10) years after the cause of action accrues. Wyoming provides one of the longest statutes of limitations for written contracts in the United States. Under WS § 1-3-105(a)(ii), actions on oral contracts must be brought within eight (8) years. All modifications to this SOW should be in writing to preserve the ten-year limitations period.
16.5 Electronic Signatures
Consistent with the Wyoming Uniform Electronic Transactions Act (WS § 40-21-101 et seq.), the Parties agree that this SOW may be executed by electronic signature, which shall have the same legal effect, validity, and enforceability as an original handwritten signature. Under WS § 40-21-107, a record or signature may not be denied legal effect or enforceability solely because it is in electronic form, and a contract may not be denied legal effect or enforceability solely because an electronic record was used in its formation.
16.6 Data Breach Notification
If Provider has access to personal identifying information (as defined by WS § 40-12-501) in the course of performing Services:
(a) Provider shall implement and maintain reasonable security measures to protect such information in compliance with Wyoming law
(b) In the event of a security breach involving personal identifying information of Wyoming residents, Provider shall notify Client within twenty-four (24) hours of discovery
(c) Provider shall cooperate with Client in complying with the notification requirements of WS § 40-12-502, which requires that upon determining that the misuse of personal identifying information has occurred or is reasonably likely to occur, the entity must give notice as soon as possible to the affected Wyoming resident
(d) The notification must be made in the most expedient time possible and without unreasonable delay, consistent with the legitimate needs of law enforcement and any measures necessary to determine the scope of the breach and restore the reasonable integrity of the computerized data system
(e) Any person maintaining computerized data on behalf of another entity shall notify the owner or licensee of the data as soon as practicable following discovery of a breach, pursuant to WS § 40-12-502(b)
(f) Provider shall bear the costs of notification and remediation to the extent the breach resulted from Provider's negligence or failure to comply with its obligations hereunder
16.7 No State Income Tax
The Parties acknowledge that Wyoming does not impose a state personal income tax or corporate income tax. Consequently, no state income tax withholding is required for payments under this SOW. However, Provider remains responsible for all applicable federal tax obligations and any other Wyoming taxes (such as sales tax under WS § 39-15-101 et seq.).
16.8 Wyoming Sales and Use Tax
Wyoming imposes a sales tax at a rate of 4.0% (WS § 39-15-104), with counties authorized to impose additional local option taxes of up to 2.0%. While most professional services are not subject to Wyoming sales tax, certain tangible personal property and specified services delivered as part of the Work Product may be subject to sales or use tax. The Parties shall cooperate to determine the applicability of sales and use taxes to the Services and Deliverables.
16.9 Non-Compete and Non-Solicitation
To the extent this SOW includes any restrictive covenants (non-competition, non-solicitation), the Parties acknowledge that Wyoming courts generally enforce reasonable non-compete agreements. Wyoming courts apply a reasonableness analysis, examining whether the restraint is necessary to protect the employer's legitimate business interests, is not unduly burdensome on the restricted party, and does not harm the public interest. Wyoming has not enacted specific non-compete statutory restrictions comparable to those in Oregon or Washington.
16.10 Mineral and Natural Resource Considerations
If the Services are related to Wyoming's mineral extraction, oil and gas, coal, or natural resource industries, the Parties shall comply with all applicable environmental regulations, including those administered by the Wyoming Department of Environmental Quality (DEQ) and the Wyoming Oil and Gas Conservation Commission. Provider shall obtain all necessary permits and comply with applicable reclamation requirements.
16.11 Jury Trial Waiver
TO THE FULLEST EXTENT PERMITTED BY WYOMING LAW, EACH PARTY HEREBY IRREVOCABLY WAIVES ALL RIGHT TO A TRIAL BY JURY IN ANY ACTION, PROCEEDING, OR COUNTERCLAIM ARISING OUT OF OR RELATING TO THIS SOW OR THE TRANSACTIONS CONTEMPLATED HEREBY.
16.12 Attorney's Fees
In any action to enforce this SOW, the prevailing Party shall be entitled to recover its reasonable attorney's fees and costs from the non-prevailing Party. The Parties acknowledge that Wyoming follows the "American Rule" (each party generally bears its own attorney's fees), and this contractual provision constitutes a knowing exception to that default rule, enforceable under Wyoming law.
17. TERMINATION
17.1 Termination for Convenience
Either Party may terminate this SOW for any reason upon [____] days' prior written notice to the other Party.
17.2 Termination for Cause
Either Party may terminate this SOW immediately upon written notice if:
(a) The other Party commits a material breach and fails to cure such breach within [____] days after receiving written notice of the breach
(b) The other Party becomes insolvent, files for bankruptcy, or makes an assignment for the benefit of creditors
(c) The other Party is dissolved, liquidated, or ceases to conduct business in the ordinary course
17.3 Effect of Termination
Upon termination or expiration of this SOW:
(a) Provider shall promptly cease performance of Services, except as necessary to effect an orderly transition
(b) Provider shall deliver to Client all completed and in-progress Work Product, Deliverables, and Client Confidential Information
(c) Client shall pay Provider for all Services satisfactorily performed and accepted through the effective date of termination, plus any non-cancellable expenses incurred prior to the termination notice
(d) Each Party shall return or destroy the other Party's Confidential Information
17.4 Transition Assistance
Upon request, Provider shall provide reasonable transition assistance to Client for a period of up to [____] days following termination, at Provider's then-current rates. Provider shall cooperate in good faith to minimize disruption to Client's operations.
18. INSURANCE
18.1 Provider Insurance Requirements
Provider shall maintain, at its own expense, the following insurance coverage during the term of this SOW and for [____] year(s) thereafter:
| Coverage Type | Minimum Amount |
|---|---|
| Commercial General Liability | $[________________________________] per occurrence / $[________________________________] aggregate |
| Professional Liability (E&O) | $[________________________________] per claim / $[________________________________] aggregate |
| Workers' Compensation | Statutory limits — Wyoming State Fund (Department of Workforce Services) |
| Employer's Liability | $[________________________________] per accident |
| Automobile Liability (if applicable) | $[________________________________] combined single limit |
| Cyber Liability (if applicable) | $[________________________________] per occurrence |
| Umbrella/Excess Liability | $[________________________________] |
18.2 Wyoming Workers' Compensation — Monopolistic State Fund
IMPORTANT: Wyoming operates a monopolistic state workers' compensation system. Provider acknowledges and agrees to the following:
(a) Wyoming's Workers' Compensation Act (WS § 27-14-101 et seq.) establishes a mandatory workers' compensation system administered by the Wyoming Department of Workforce Services, Workers' Compensation Division
(b) Private workers' compensation insurance is not available in Wyoming. Employers must obtain coverage exclusively through the Wyoming Workers' Compensation Division state fund. Wyoming does not permit employers to purchase workers' compensation coverage from private insurance carriers
(c) No self-insurance option: Unlike Washington (the other monopolistic state addressed in this repository), Wyoming does not permit employer self-insurance for workers' compensation. All coverage must be obtained through the state fund
(d) Provider shall maintain an active and current account with the Wyoming Workers' Compensation Division and pay all required premiums for all employees performing Services under this SOW. Pursuant to WS § 27-14-201, any employer subject to the act shall not commence business or engage in work without applying for coverage and receiving a statement of coverage from the Division
(e) Coverage is determined by the employer's industry classification using the North American Industry Classification System (NAICS). Industries classified as "extra-hazardous" under WS § 27-14-108 are required to carry coverage; other industries may elect coverage voluntarily
(f) Provider represents that its Wyoming Workers' Compensation account is in good standing and not subject to any penalties or delinquencies. Provider's Wyoming WC Account Number is: [________________________________]
(g) Subcontractor Compliance: If Provider uses subcontractors to perform Services, Provider shall ensure that all subcontractors maintain active Wyoming workers' compensation coverage. Under WS § 27-14-104, the exclusive remedy provisions of the Workers' Compensation Act apply, and employers may be held liable for injuries to employees of uninsured subcontractors
18.3 Certificates of Insurance
Provider shall furnish Client with certificates of insurance evidencing the coverage required herein prior to commencement of Services and upon renewal. Certificates shall name Client as an additional insured under the commercial general liability and umbrella/excess policies. For workers' compensation, Provider shall provide a copy of its Wyoming Workers' Compensation Division account verification or certificate of coverage.
18.4 No Limitation of Liability
Maintenance of insurance shall not limit Provider's liability under this SOW.
19. DISPUTE RESOLUTION
19.1 Negotiation
The Parties shall first attempt to resolve any dispute arising out of or relating to this SOW through good-faith negotiation between their designated representatives for a period of [____] business days.
19.2 Mediation
If negotiation fails, the Parties agree to submit the dispute to non-binding mediation administered by ☐ the American Arbitration Association (AAA) ☐ JAMS ☐ a mutually agreed mediator in [________________________________] County, Wyoming. The costs of mediation shall be shared equally.
19.3 Arbitration (if selected)
☐ Binding Arbitration: If mediation fails, the dispute shall be resolved by binding arbitration administered by ☐ AAA ☐ JAMS in [________________________________] County, Wyoming, in accordance with the applicable rules. The arbitrator's decision shall be final and binding and may be entered as a judgment in any court of competent jurisdiction in Wyoming. Arbitration shall be conducted in accordance with the Wyoming Uniform Arbitration Act (WS § 1-36-101 et seq.).
☐ Litigation: If mediation fails, either Party may pursue litigation in the courts specified in Section 16.2.
19.4 Injunctive Relief
Notwithstanding the foregoing, either Party may seek injunctive or other equitable relief from any court of competent jurisdiction to prevent irreparable harm, including but not limited to breaches of confidentiality, intellectual property infringement, or misappropriation of trade secrets under the Wyoming Uniform Trade Secrets Act (WS § 40-24-101 et seq.).
19.5 Continued Performance
Unless otherwise agreed, the Parties shall continue to perform their obligations under this SOW during the pendency of any dispute resolution proceedings.
20. GENERAL PROVISIONS
20.1 Entire Agreement
This SOW, together with any Master Agreement referenced herein and all exhibits and attachments, constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes all prior or contemporaneous oral or written agreements concerning such subject matter.
20.2 Amendments
This SOW may not be modified except by a written instrument signed by authorized representatives of both Parties.
20.3 Severability
If any provision of this SOW is held to be invalid, illegal, or unenforceable by a court of competent jurisdiction in Wyoming, the remaining provisions shall continue in full force and effect, and the Parties shall negotiate in good faith to replace the invalid provision with a valid provision that most closely approximates the intent of the original.
20.4 Waiver
No waiver of any provision of this SOW shall be effective unless in writing and signed by the waiving Party. No failure or delay in exercising any right shall operate as a waiver thereof.
20.5 Assignment
Neither Party may assign this SOW without the prior written consent of the other Party, except that either Party may assign this SOW to an affiliate or in connection with a merger, acquisition, or sale of all or substantially all of its assets. Any assignment in violation of this provision shall be void.
20.6 Independent Contractor
Provider is an independent contractor and nothing in this SOW shall be construed to create a partnership, joint venture, agency, or employment relationship between the Parties. Provider shall be solely responsible for the compensation, benefits, and tax obligations of its personnel.
20.7 Force Majeure
Neither Party shall be liable for any failure or delay in performance due to causes beyond its reasonable control, including acts of God, war, terrorism, pandemic, epidemic, government restrictions, natural disaster, fire, flood, blizzard, earthquake, power failure, internet outage, or labor dispute (each, a "Force Majeure Event"). The affected Party shall promptly notify the other Party and use commercially reasonable efforts to mitigate the impact.
20.8 Notices
All notices shall be in writing and delivered to the addresses set forth in the Parties section by:
☐ Personal delivery
☐ Certified mail, return receipt requested (U.S. Postal Service)
☐ Overnight courier with tracking (e.g., FedEx, UPS)
☐ Email (with read receipt or delivery confirmation)
Notices shall be deemed received upon actual receipt (personal delivery), three (3) business days after mailing (certified mail), one (1) business day after deposit (overnight courier), or upon confirmed delivery (email). Parties should account for potential weather-related mail delays in rural Wyoming locations.
20.9 Counterparts
This SOW may be executed in counterparts, each of which shall be deemed an original, and all of which together shall constitute one and the same instrument. Facsimile, PDF, and electronic signatures shall be deemed originals for all purposes.
20.10 Survival
The provisions of Sections 11 (Intellectual Property), 12 (Confidentiality), 13 (Warranty), 14 (Indemnification), 15 (Limitation of Liability), 16 (Wyoming-Specific Provisions), and 20 (General Provisions) shall survive the expiration or termination of this SOW.
20.11 No Third-Party Beneficiaries
This SOW is for the sole benefit of the Parties and their permitted successors and assigns. Nothing herein shall confer any rights or remedies upon any third party.
20.12 Compliance with Laws
Each Party shall comply with all applicable federal, state, and local laws, regulations, and ordinances in the performance of its obligations under this SOW, including but not limited to Wyoming employment laws, tax obligations, environmental regulations, and anti-discrimination statutes.
21. EXHIBITS AND ATTACHMENTS
The following exhibits and attachments are incorporated by reference and made a part of this SOW:
☐ Exhibit A: Detailed Technical Specifications
☐ Exhibit B: Project Schedule (Gantt Chart)
☐ Exhibit C: Rate Card / Fee Schedule
☐ Exhibit D: Insurance Requirements
☐ Exhibit E: [________________________________]
☐ Exhibit F: [________________________________]
22. SIGNATURES
IN WITNESS WHEREOF, the Parties have executed this Statement of Work as of the Effective Date first written above.
CLIENT:
Signature: [________________________________]
Printed Name: [________________________________]
Title: [________________________________]
Date: [__/__/____]
PROVIDER:
Signature: [________________________________]
Printed Name: [________________________________]
Title: [________________________________]
Date: [__/__/____]
CHANGE ORDER LOG
| CO # | Date | Description | Cost Impact | Schedule Impact | Approved By |
|---|---|---|---|---|---|
| CO-001 | [__/__/____] | [________________________________] | $[____] | [____] days | [____] |
| CO-002 | [__/__/____] | [________________________________] | $[____] | [____] days | [____] |
| CO-003 | [__/__/____] | [________________________________] | $[____] | [____] days | [____] |
This Statement of Work is subject to all terms and conditions of the Master Agreement between the Parties dated [__/__/____], if any. In the event of any conflict between this SOW and the Master Agreement, the Master Agreement shall control unless this SOW expressly states otherwise.
Do more with Ezel
This free template is just the beginning. See how Ezel helps legal teams draft, research, and collaborate faster.
AI that drafts while you watch
Tell the AI what you need and watch your document transform in real-time. No more copy-pasting between tools or manually formatting changes.
- Natural language commands: "Add a force majeure clause"
- Context-aware suggestions based on document type
- Real-time streaming shows edits as they happen
- Milestone tracking and version comparison
Research and draft in one conversation
Ask questions, attach documents, and get answers grounded in case law. Link chats to matters so the AI remembers your context.
- Pull statutes, case law, and secondary sources
- Attach and analyze contracts mid-conversation
- Link chats to matters for automatic context
- Your data never trains AI models
Search like you think
Describe your legal question in plain English. Filter by jurisdiction, date, and court level. Read full opinions without leaving Ezel.
- All 50 states plus federal courts
- Natural language queries - no boolean syntax
- Citation analysis and network exploration
- Copy quotes with automatic citation generation
Ready to transform your legal workflow?
Join legal teams using Ezel to draft documents, research case law, and organize matters — all in one workspace.